Loading...
Serving Port Orange, FL and surrounding areas. (386) 284-1782
Effective Date: January 1, 2026
By accessing or using the website located at portorangesunrooms.com (the "Site") or by engaging Port Orange Lanai Sunrooms & Patios ("we," "us," or "our") for services, you agree to be bound by these Terms and Conditions. If you do not agree to these terms, please do not use the Site or engage our services.
We reserve the right to modify these Terms at any time. Changes take effect when posted to the Site. Continued use of the Site or our services after changes are posted constitutes your acceptance of the updated Terms.
Port Orange Lanai Sunrooms & Patios provides sunroom construction, patio enclosure, screen room installation, and related home improvement services to residential customers in Port Orange, Florida, and surrounding service areas. Services are performed on a project-by-project basis pursuant to a written agreement between the homeowner and Port Orange Lanai Sunrooms & Patios.
Information on this Site regarding services, materials, and processes is provided for general informational purposes only. It does not constitute a binding offer or guarantee of availability. Service availability is subject to location, scheduling, and project suitability assessments.
Any estimate provided by Port Orange Lanai Sunrooms & Patios - whether given by phone, email, or in person - is not a binding contract. It represents our best assessment of cost based on information available at the time of the estimate. Actual project costs may differ based on site conditions discovered during construction, changes in material pricing, or scope modifications requested by the homeowner.
A written, itemized proposal will be provided before work begins. Work does not commence until the homeowner has reviewed and signed the written agreement. Any scope changes after contract execution must be agreed upon in writing before additional work proceeds.
Project start dates are subject to permit approval timelines, material availability, and crew scheduling. We will communicate estimated start dates and notify you of any significant changes as promptly as possible.
If you need to cancel or postpone a scheduled project, please notify us in writing as early as possible. Cancellation terms, including any deposits that may be non-refundable after certain milestones, will be specified in your written project agreement. We reserve the right to reschedule work due to weather conditions, permitting delays, or other circumstances beyond our reasonable control.
Payment terms are set forth in each individual project agreement. In general, projects require a deposit at the time of contract signing, with progress payments tied to construction milestones and a final payment upon project completion and homeowner acceptance.
Invoices are due upon receipt unless otherwise stated in the project agreement. Late payments may be subject to interest charges and may result in a suspension of work until the outstanding balance is resolved. All pricing is in U.S. dollars.
Port Orange Lanai Sunrooms & Patios will obtain required building permits for contracted work in accordance with applicable local, county, and state requirements. Permit fees, where applicable, are the responsibility of the homeowner and will be itemized in the project proposal.
Homeowners are responsible for ensuring their property complies with any applicable homeowners association (HOA) rules before work begins. We are not responsible for delays or costs resulting from a homeowner's failure to obtain required HOA approvals.
Any warranty on workmanship or materials will be specified in the written project agreement. Manufacturer warranties on materials and products are passed through to the homeowner as provided by the respective manufacturers.
THE SITE AND ITS CONTENT ARE PROVIDED "AS IS" WITHOUT ANY WARRANTY OF ANY KIND, EXPRESS OR IMPLIED. We do not warrant that the Site will be error-free or uninterrupted, or that information on the Site is accurate, complete, or current. No warranty is made regarding the results that may be obtained from use of the Site.
To the fullest extent permitted by applicable law, Port Orange Lanai Sunrooms & Patios shall not be liable for any indirect, incidental, special, consequential, or punitive damages arising from your use of the Site, your reliance on information contained on the Site, or any delay or failure in performance of services beyond our reasonable control.
Our total liability for any claim arising out of or related to these Terms or our services shall not exceed the amount actually paid by you to Port Orange Lanai Sunrooms & Patios for the specific service giving rise to the claim.
All content on this Site - including text, images, logos, and design elements - is the property of Port Orange Lanai Sunrooms & Patios or its content suppliers and is protected by applicable intellectual property laws. You may not reproduce, distribute, or use any content from this Site without our prior written permission.
We encourage you to contact us directly if you have a concern about our services or this Site. Most issues can be resolved through direct communication. If a dispute cannot be resolved informally, the parties agree to attempt good-faith mediation before pursuing other remedies.
Nothing in these Terms prevents either party from seeking injunctive or other equitable relief in a court of competent jurisdiction where appropriate to prevent irreparable harm.
These Terms and Conditions are governed by and construed in accordance with the laws of the State of Florida, without regard to its conflict of law provisions. Any legal action or proceeding arising out of or related to these Terms shall be brought exclusively in the state or federal courts located in Florida.
If you have questions about these Terms and Conditions, please contact us: